Quotation DATE: QUOTE NO: ACCOUNT: REFERENCE: ATTENTION:
07/10/16 Q42282 COD0324 DC
PROF. L N JUSTIN WCCC PRIVATE HOSPITAL PORTION 117 BRANDVLEI RANDFONTEIN GAUTENG
TEL: E-MAIL:
063 036 7015036 701563 036 7015
[email protected]
SALES PERSON
DIVISION
QUOTE DELIVERY
QUOTE VALIDITY
EXPIRY DATE
CHERINE RABIE
EMED
E-MAIL
30 DAYS
06/11/16
EXAMINATION TABLE
ITEM NO. OE88
DESCRIPTION EXAMINATION COUCH
QTY 1
UNIT LIST PRICE EX VAT 1,983.95
DISC %
NET AFTER DISCOUNT 1,983.95
LINE TOTAL EX VAT 1,983.95
TOTAL EX. VAT VAT
1,983.95 277.75
TOTAL INCL. VAT
2,261.70
PATIENT TROLLEY
201412 189621 191954
MOBILO 2G PATIENT TROLLEY 4SECTION IN ARGENTUM INFUSION ROD (STAINLESS STEEL) WITH 3 TILTABLE HOOKS PUSH GRIPS/HANDLES FOR THE MOBILO.
1
34,210.15
34,210.15
34,210.15
1
1,832.50
1,832.50
1,832.50
1
1,395.40
1,395.40
1,395.40
TOTAL EX. VAT VAT
37,438.05 5,241.33
TOTAL INCL. VAT
42,679.38
HOSPITAL BED
206900
VIDA II – FULLY ELECTRIC 4-SECTION BED COMPLETE WITH ¾ SAFETY SIDES AND INTERCONTINENTAL HEAD & FOOT BOARD DESIGN
1
26,399.21
26,399.21
26,399.21
221932 LS
ROBUST FOAM MATTRESS
1
3,823.75
3,823.75
3,823.75
218682
SORENO ECO BEDSIDE LOCKER WITH EATING TABLE & 2 DRAWERS
1
6,375.00
6,375.00
6,375.00
TOTAL EX. VAT VAT
36,597.96 5,123.71
TOTAL INCL. VAT
41,721.68
121 Gazelle Avenue, Corporate Park South, Midrand • Private Bag X31, Halfway House, 1685 Tel: 011 314 0503 • Fax: 011 314 0098 •
[email protected] Marcus Medical (Pty) Ltd Reg No: 1965/02407/07 Directors: M P Goldberg, O E Goldberg, A E Trappitt An Imaging International Group Company
Quotation EXAMINATION LIGHT
SunLED 300C
SunLED 300 Ceiling Mounted Single head light 35,000 lux at 1 Meter
1
28,143.36
28,143.36
28,143.36
INSTALLATION
1
5,000.00
5,000.00
5,000.00
TOTAL EX. VAT VAT
33,143.36 4,640.07
TOTAL INCL. VAT
37,783.43
ECG MACHINE
IE12
IE12 Twelve-channel Intelligent Electrocardiograph Trolley
1
23,452.80
23,452.80
23,452.80
1
3,133.33
3,133.33
3,133.33
TOTAL EX. VAT VAT
26,586.13 3,722.06
TOTAL INCL. VAT
30,308.19
OBSTETRIC AND DELIVERY BED
C600K/SND
1
265,333.25
265,333.25
265,333.25
PA46.01
Electric Surgical Table, with built-in kidney elevator, auto leveling, 30cm longitudinal sliding and 52cm low profile Lithotomy leg holder
2
6,385.02
6,385.02
12,770.04
PA01.01
Redial setting clamp
2
2,554.01
2,554.01
5,108.02
PA06.02
Arm board
2
4,256.68
4,256.68
8,513.36
PA03.01
Anesthesia screen
1
2,128.34
2,128.34
2,128.34
PA01.01
Redial setting clamp
1
2,554.01
2,554.01
2,554.01
TOTAL EX. VAT VAT
296,407.04 41,496.99
TOTAL INCL. VAT
337,904.03
OPTIONAL ACCESSORIES
PA85.01
45 cm table width extension
1
6,385.02
6,385.02
6,385.02
PA16.02
Drain Pan
1
5,675.58
5,675.58
5,675.58
PA08.02
Leg Holder
2
4,256.68
4,256.68
8,513.36
PA01.01
Redial setting clamp
2
2,554.01
2,554.01
5,108.02
PA11.01
Retraint Strap
1
2,128.34
2,128.34
2,128.34
1
13,602.62
13,602.62
13,602.62
INFUSION PUMP
SP7700
IP-7700 Volumetric Infusion Pump
TOTAL EX. VAT VAT
13,602.62 1,904.37
TOTAL INCL. VAT
15,506.99
121 Gazelle Avenue, Corporate Park South, Midrand • Private Bag X31, Halfway House, 1685 Tel: 011 314 0503 • Fax: 011 314 0098 •
[email protected] Marcus Medical (Pty) Ltd Reg No: 1965/02407/07 Directors: M P Goldberg, O E Goldberg, A E Trappitt An Imaging International Group Company
Quotation IV POLE
OE68/4 STR
4 Leg Drip Stand epoxy coated with stainless steel T rod
1
1,450.84
1,450.84
1,450.84
TOTAL EX. VAT VAT
1,450.84 203.12
TOTAL INCL. VAT
1,653.96
SUCTION MACHINE
Q141/1-1
VORTECO AS100/30LT (1 jar lt.1)
1
7,186.89
7,186.89
7,186.89
GP/F
Bacterial Filter (10)
1
496.24
496.24
496.24
TOTAL EX. VAT VAT
7,683.13 1,075.64
TOTAL INCL. VAT
8,758.76
VITAL SIGNS MONITORS
20.11-5200S
TRO
SpO2, NIBP, Temperature . More accurate blood pressure(Suntech NIBP module installed) . Built-in Li-ion Rechargeable Battery . Optional Central Monitoring System(wired/wireless) . Standard accessories 1 X Reusable Adult SpO2 Probe, 1 X SpO2 Probe Extension Cable 1 X Adult NIBP cuff, 1 X NIBP Extension Tube 1 x Temperature Probe Mobile trolley
1
31,309.49
31,309.49
31,309.49
1
3,133.33
3,133.33
3,133.33
TOTAL EX. VAT VAT
34,442.82 4,821.99
TOTAL INCL. VAT
39,264.82
Customer Acceptance Order No: __________________________ Customer Signature:__________________ Date:______________________________
Min order Value of R1000 for Free delivery. Delivery times to major city centres in South Africa will take 48hrs. All other area’s will take 72 to 96 hours. Should you require shorter delivery an additional delivery charge will incur.
121 Gazelle Avenue, Corporate Park South, Midrand • Private Bag X31, Halfway House, 1685 Tel: 011 314 0503 • Fax: 011 314 0098 •
[email protected] Marcus Medical (Pty) Ltd Reg No: 1965/02407/07 Directors: M P Goldberg, O E Goldberg, A E Trappitt An Imaging International Group Company
MARCUS MEDICAL (PTY) LIMITED (MARCUS) TERMS AND CONDITIONS OF SALE QUOTE REFERENCE: Q42282
DATE: 07 October 2016
New equipment offered by MARCUS is guaranteed against defective material and workmanship for a period not exceeding fifteen (15) months from delivery date of equipment to site or twelve (12) months from completion of installation, whichever is sooner. This guarantee is not valid if servicing or repairs during the guarantee period are undertaken by companies / persons unauthorized by MARCUS and is subject to the following conditions: Twelve (12) months from delivery date on a pro-rata basis or twelve (12) months pro-rata, whichever occurs first), subject to factory inspection and report. Wear and tear parts excluding consumables - Twelve (12) months pro-rata. Glass parts breakage or operator mechanical damage excluded from guarantee. NB: Annual QC tests are not included in the warranty. SERVICE CONTRACT Service contracts inside and out of the guarantee periods are highly recommended. We shall be pleased to discuss the advantages of the MARCUS Preventative Maintenance Service Contract. FREE SERVICE Service during the guarantee period will be free, subject to the following: Note Free service during any of the above guarantee periods only applies if the call-out is a result of apparatus, equipment or component failure and not as a result of misuse or operator error. Erroneous calls will be charged at MARCUS ruling labour and transport rates. DEPARTMENT OF HEALTH: DIRECTORATE: RADIATION CONTROL – SOUTH AFRICA Before purchasing any x-ray equipment a RC001 application form for a “Licence in terms of article 4 of the Hazardous Substances Act 1973 (Act 15 of 1973) to use a x-ray device” must be completed and submitted to the Directorate: Radiation Control for approval. MARCUS will assist in completing the form and provide all information regarding the offered equipment and after sales service and quality control requirements. MARCUS will not be responsible for supply, installation, commissioning, deinstallation and / or removal of equipment where the Customer / Purchaser fails to obtain the applicable licence(s). PRICES Prices are quoted in S.A. Rand and are understood net, delivered and installed, unless otherwise stated herein, but are subject to currency variation/s on the imported content of the equipment, based on the exchange rate/s of :EURO 1.00 = R15.18 USD 1.00 = 13.67 Any escalation in costs due to unforeseen circumstances either attributable to ANY shipping delays, or other delays i.e. lost apparatus, partially delivered goods, damaged goods, incomplete site preparation, technicians unable to complete the installation etc. will incur additional costs for the Customer’s / Purchaser’s account. INSTALLATION Prices quoted include installation within a 200 km radius of any MARCUS Service Centre. Distances over 200 km will incur travelling time, transport charges and accommodation at MARCUS ruling rates unless otherwise stated. TERMS OF PAYMENT & COSTS Terms of Payment are strictly seven (7) days net from date of invoice and MARCUS reserves the right to charge interest at two percent (2%) above the prevailing prime lending rate of South African Commercial Banks on all accounts exceeding this seven (7) day period, calculated daily and compounded monthly. Payment for delivery and / or installation outside of South Africa to be made by Irrevocable and Confirmed Letter of Credit made payable to MARCUS. The Customer / Purchaser shall be liable for any and all costs incurred by MARCUS to recover the goods and / or secure payment of its invoices on at least the attorney and client scale.
1
CANCELLATION OF ORDERS Orders are firm and not subject to cancellation. Where cancellation of an order is accepted in writing by MARCUS, the Customer / Purchaser will become liable for a cancellation fee of ten percent (10%) of the invoiced value of the goods, plus the cost of shipping the goods back to the factory in the country of origin. LIABILITY Equipment supplied by MARCUS or through any MARCUS appointed dealer, if proved defective will be repaired / replaced at MARCUS option and in accordance with MARCUS terms of guarantee. MARCUS or any of its suppliers shall have no other or greater liability of any kind for any damage or loss, direct, incidental or consequential, regardless of legal theory, including strict liability and negligence. The foregoing may not be altered, except by written agreement, signed by MARCUS and seller. All Customer / Purchaser orders are subject to the above terms of sale. OWNERSHIP & RISK Ownership of the goods shall remain vested in MARCUS and shall pass only on payment of the full purchase price having been received by MARCUS. Notwithstanding the above, risk in and to the goods shall pass to the Customer upon delivery thereof and the Customer undertakes to insure the goods for their full replacement value for so long as the full purchase price owing to MARCUS remains unpaid. If the goods are purchased: through a third party or an MARCUS appointed dealer; or by the Customer with the assistance of a finance house (“the Purchaser”) the Customer and / or the Purchaser, notwithstanding delivery of the good, shall not acquire ownership thereof until MARCUS has received payment of the full purchase price, aforesaid. While MARCUS remains owner of the goods, the Customer and / or Purchaser shall grant MARCUS, its employees, agents or assigns access to the goods at all reasonable times to inspect same whosesoever the goods may be situated and the Customer and / or Purchaser shall, within two days of delivery of the goods, provide MARCUS with written proof that it has notified the Customer’s landlord that same are owned by MARCUS, are not subject to the Landlord’s tacit hypothec and that MARCUS may at any time enter upon the premises where the goods are kept to secure and remove the goods should the Customer fail to make any payment contemplated herein related to it purchasing the goods. BREACH An event of default shall occur if the Customer and / or Purchaser: should fail to make payment of the full purchase price for the goods; or breach any of these terms (all of which you agree to be material); or should act in any way which is referred to as an act of insolvency in the Insolvency Act; or allow any judgment against you to remain unsatisfied for a period of fourteen (14) days, unless an appeal or application for rescission has been noted against such judgment; or should compromise or attempt to compromise or delay payment of any debt owing by you to any of your creditors; or should you act in any way which may prejudice MARCUS’s rights in terms hereof; or should the goods be lost, damaged or destroyed and MARCUS determines, in its sole discretion, that the goods are uneconomical to repair. In the event of default and where MARCUS has not received payment in full for the goods, MARCUS shall, without prejudice to any of its other rights: be entitled to claim immediate payment of all amounts owing to it, whether then due for payment or not; or cancel the sale of the goods without notice to you, obtain possession of the goods and recover from you, as pre-estimated liquidated damages, the total amount of payables not yet paid by you, whether same are due for payment or not less the proceeds of the sale of the goods or the proceeds of any insurance policy paid to MARCUS in respect of the goods.
2
DOMICILIUM CITANDI ET EXECUTANDI & LEGAL PROCEEDINGS The Customer / Purchaser hereby nominates as its chosen domicilium citandi et executandi as the physical address where the goods are delivered MARCUS alternatively such other physical address where the goods are normally situated from time to time as the address where MARCUS may serve summonses, legal documents and notices upon you. In the event that MARCUS instructs its attorneys to take legal action related to these Terms and Conditions or any transaction regulated hereby, the Customer / Purchaser shall be liable for MARCUS’s costs on the attorney and client scale. STRUCTURAL ALTERATIONS This quotation excludes structural alterations to premises, provision of main supply, ducting, conduits, beams or plumbing of any nature unless agreed to in writing and incorporated herein. SURCHARGE / TAX / VAT This quotation, unless specifically indicated to the contrary, excludes surcharge, general sales tax, value-added tax or any duty imposed by Government bodies. VALIDITY All quotations shall remain valid for a period of 30 (thirty)calender days only. Thereafter is subject to written confirmation by MARCUS alternatively the issuing of an invoice in respect of the order received DELIVERY TIME (Delivery time is as shown below, however, shorter delivery periods are possible, subject to confirmation at placement of official order) Ex principal works / factory at time of this quotation is given as 8-10 weeks. Due to adverse factors that can cause deviations, a final delivery period will be confirmed to you after receipt of your official order. MARCUS is not responsible and will not be held liable, for any damages whatsoever, arising from delays or non-delivery through any causes beyond its control, particularly, but not limited to, such as may be caused by the Government or Military Authorities, civil unrest, labour action, electrical or communication failures / disruptions, failure of transport or delayed arrival of negotiable documents, goods, Force Majeur, etc. GENERAL This document contains the complete terms and conditions upon which MARCUS sells the goods to the Customer / Purchaser and no changes may be made hereto unless in writing and signed by yourself and MARCUS. Purchase orders raised against this quote will automatically be subject to our terms and conditions, irrespective of whether our terms and conditions have been signed.
ALAN TRAPPITT MANAGING DIRECTOR
RUI MARTINS NEW BUSINESS DEVELOPMENT MANAGER
Signed for and on behalf of MARCUS (PTY) LIMITED
I / We hereby accept the above terms and conditions of sale
____________________________________ CUSTOMER / PURCHASER SIGNATURE
_________________________ DATE
NAME ___________________________ POSITION ________________________
PLEASE INDICATE YOUR SELECTION BY THE APPROPRIATE BOX:YES I REQUIRE FORWARD COVER NO I DO NOT REQUIRE FORWARD COVER
3
IN
4